Senate
House
Joint
Bill Status
WV Code
Audits/ Reports
Educational
Contact
home
home

Introduced Version Senate Bill 437 History

DOWNLOAD  wpd  |  Email


sb437 intr
Senate Bill No. 437

(By Senator McCabe)

____________

[Introduced March 3, 2005; referred to the Committee

on Finance.]

____________




A BILL to amend the Code of West Virginia, 1931, as amended, by adding thereto a new section, designated §5-22-3, relating to requiring contractors awarded state public works construction projects to meet time restrictions for the completion of a public works construction project; defining "public works construction contract"; providing a monetary penalty for failure to complete a public works construction project on the agreed-upon completion date; providing exceptions in which extensions may be granted; providing limitations upon an increase in contract price, or extension of time to complete a project, in the event of change orders; and directing the Secretary of the Department of Administration to propose legislative rules designed to implement the law.

Be it enacted by the Legislature of West Virginia:
That the Code of West Virginia, 1931, as amended, be amended by adding thereto a new section, designated §5-22-3, to read as follows:
ARTICLE 22. GOVERNMENT CONSTRUCTION CONTRACTS.
§5-22-3. Requirement of on-time completion of construction contracts.

(a) Every public works construction contract shall include a provision which requires the contractor awarded the contract to complete the construction project by an agreed-upon completion date. For the purposes of this section,
"public works construction contract" means any contract between a private contractor and any public agency of this state for the construction, reconstruction, establishment, acquisition, improvement, renovation, extension, enlargement, increase, equipment, maintenance and repair (including replacements) of facilities, buildings, engineering and architectural works, museums, other public buildings, incinerator plants, land fill or other garbage disposal systems, hospitals, piers, docks, terminals, airports, drainage systems, flood control systems, floodwalls, sewers, culverts, bridges (including approaches, causeways, viaducts, underpasses and connecting roadways), public markets, cemeteries, motor vehicle parking facilities (including parking lots, buildings, ramps, curb-line parking, meters and other facilities deemed necessary, appropriate, useful, convenient or incidental to the regulation, control and parking of motor vehicles), stadiums, gymnasiums, sports arenas, auditoriums, public recreation centers, public recreation parks, swimming pools, roller skating rinks, ice skating rinks, tennis courts, golf courses, polo grounds, or other public improvements, or the grading, regrading, paving, repaving, surfacing, resurfacing, curbing, recurbing, widening or otherwise improving of any highway, street, avenue, road, alley, sidewalk, way, and any other structure, facility or improvement constructed or undertaken by a public agency.
(b) All public works construction contracts shall include a provision requiring completion of the project by a certain date, including a monetary penalty of not less than one thousand dollars per day for every day that passes beyond the agreed-upon completion date.
(c) A request for an extension of time beyond an agreed upon completion date may only be granted in the event of an unforeseeable emergency, to accommodate significant changes made by the public agency with which the contract exists, or because of the fortuitous existence of extreme inclement weather conditions: Provided, That, for the purpose of this section "extreme inclement weather conditions" means the existence of meteorological elements and conditions that vary, at least ten percent beyond the average meteorological elements and conditions for the particular temporal period at issue, based on the recorded meteorological elements and conditions of the previous ten years, which so demonstrably hamper the necessary activities for completion of the project, consistent with applicable industry standards, that the requirement of completion on the agreed upon date becomes unreasonable.
(d) In the event of change orders for related additional services, extensions may not be granted which exceed twenty percent, either as to an increase to the original contract price, or as to an extension of time relative to the agreed upon completion date: Provided, That in the event an additional service is expressly included as an option in the original contract, the restrictions contained in this subsection do not apply unless expressly provided for in the contract.
(e) The Secretary of the Department of Administration shall propose rules for legislative approval in accordance with the provisions of article three, chapter twenty-nine-a of this code designed to implement the provisions of this section.



NOTE: The purpose of this bill is to
require that each state public works contract include a provision requiring a definitive completion date and that contractors awarded such contracts be required to meet the time restriction. The bill also defines "public works construction contract" and provides a monetary penalty for failure to complete a public works construction project on the agreed-upon completion date. It also provides exceptions in which extensions may be granted while providing limitations upon an increase in the contract price or extension of time to complete a project in the event of change orders. Finally, it directs the Secretary of the Department of Administration to propose legislative rules designed to implement the law.

This section is new; therefore, strike-throughs and underscoring have been omitted.
This Web site is maintained by the West Virginia Legislature's Office of Reference & Information.  |  Terms of Use  |   Web Administrator   |   © 2014 West Virginia Legislature **